The AIA A305 form is a standardized document used in the construction industry to provide a contractor's qualifications. It helps owners and architects assess a contractor's experience, financial stability, and overall capability to complete a project. For those looking to streamline their project bidding process, filling out this form is an essential step—click the button below to get started.
The AIA A305 form is primarily used to gather information about a contractor's qualifications. This includes their experience, financial stability, and overall capability to complete a project.
Completing the form accurately is essential. Inaccurate or incomplete information can lead to disqualification from bidding opportunities or damage to a contractor's reputation.
Contractors should provide detailed descriptions of past projects. Highlighting relevant experience can significantly enhance the credibility of the submission.
Financial information is a critical component. Contractors must be prepared to disclose financial statements, which demonstrate their ability to manage project costs effectively.
Using the A305 form can improve a contractor's chances of winning bids. A well-completed form serves as a strong marketing tool, showcasing qualifications to potential clients.
The AIA A305 form is a crucial document used in construction projects, primarily serving as a contractor's qualification statement. When working with this form, several other documents may also be utilized to ensure a comprehensive understanding of the contractor's qualifications and the project's requirements. Below is a list of related forms and documents that are commonly used alongside the AIA A305.
Utilizing these documents in conjunction with the AIA A305 form can help streamline the construction process, clarify responsibilities, and ensure all parties are aligned on the project's scope and financial aspects. Proper documentation is essential for a successful project outcome.
The AIA A305 form, also known as the Contractor's Qualification Statement, is a vital document in the construction industry. It helps contractors showcase their qualifications and experience. There are several other documents that serve similar purposes, each offering unique insights into a contractor's capabilities. Here are six documents that are comparable to the AIA A305 form:
Bill of Sale - A Texas Bill of Sale is essential for documenting the sale of personal property, ensuring both buyer and seller are protected during the transaction. For more information, visit documentonline.org/blank-texas-bill-of-sale.
When to Renew Australian Passport - Priority processing is available for an additional fee, with a two working day turnaround.
A California Living Will form, often referred to as an advance healthcare directive, allows a person to document their preferences for medical treatment in the event they are unable to communicate their wishes. This legal document plays a crucial role in end-of-life planning, ensuring that a person's medical treatment preferences are respected. By preparing a Living Will, individuals can provide clear instructions regarding their healthcare, avoiding potential family disputes and ensuring their dignity is maintained during critical moments. For more resources, you can also explore All California Forms.
What Happens If Dog Vaccination Is Delayed - Easy reference for veterinarians when treating your dog.
Incomplete Information: Many individuals forget to fill out all required sections of the AIA A305 form. This can lead to delays or even rejection of the application. Ensure every section is completed accurately.
Incorrect Financial Data: Providing outdated or incorrect financial information is a common mistake. It’s crucial to use the most recent financial statements to reflect your current situation.
Failure to Sign: Neglecting to sign the form can invalidate your submission. Always double-check that all necessary signatures are present before sending the form.
Omitting Supporting Documents: Some people forget to include required attachments, such as proof of insurance or financial references. Review the checklist to ensure all documents are submitted.
Not Reviewing for Errors: Rushing through the form can lead to typos or misstatements. Take the time to review your entries for accuracy and clarity before submission.
AlA Document A305" - 1986
Contractor's Qualification Statement
The Undersigned certifies under oath that the information provided herei n is true and sufficiently complete so as not to be misleading.
SUBMITTED TO:
ADDRESS:
SUBMITTED BY:
NAME:
PRINCIPAL OFFICE:
ADDITIONS AND DELETIONS:
The author of this document has added information needed for its completion. The author may also have revised the text of the original AlA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed . A vertical line in the left margin of this document indicates where the author has added necessary information and where the author has added to or deleted from the original AlA text.
This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification.
Corporation
This form is approved and
Partnership
recommended by the American
Individua l
Institute of Architects (AlA) and
The Associated General
Joint Venture
Contractors of America (AGC) for
use in evaluating the
Other
qualifications of contractors . No
endorsement of the submitting
NAME OF PROJECT
(if applicable):
party or verification of the
information is made by AlA or
AGC.
TYPE OF WORK (file separate form for each Classification of Work ):
General Construction
HVAC
Electrical
Plumbing
Other (please specify)
AlA Document A305™ -1 986. Copyright © 1964,1969,1979 and 1986 by The American Institute of Architects. All rights reserved. WARNING: This
1
AfA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AlA
Document, or
any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This
document was produced by AlA software at 13:28:18 on 03/22/2006 under Order No.1000201877_ 1 which expires on 10/11 /2006 , and is not for resale.
User Notes:
(2533789901)
§1. ORGANIZATION
§1.1 How many years has your organization been in business as a Contractor?
§1.2 How many years has your organization been in business under its present business name?
§1.2.1 Under what other or former names has your organization operated?
§1.3 If your organization is a corporation, answer the following:
§1.3.1 Date of incorporation:
§1.3.2 State of incorporation:
§1.3.3 President's name:
§1.3.4 Vice-president's name(s)
§1.3.5 Secretary's name:
§1.3.6 Treasurer's name:
§1.4 If your organization is a partnership, answer the following:
§1.4.1 Date of organization:
§1.4.2 Type of partnership (if applicable):
§1.4.3 Name(s) of general pa11ner(s)
§1.5 If your organization is individually owned, answer the following:
§1.5.1 Date of organization:
AIA Document A305™ -1986. Copyright© 1964, 1969, 1979 and 1986 by The American Institute of Architects. All rights reserved. WARNING: This
2
AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA
any portion of It, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This
document was produced by AIA soltware at 13:28:18 on 03/22/2006 under Order No.1000201877_1 which expires on 10/11/2006, and is not for resale.
§1.5.2 Name of owner:
§1.6 If the form of your organization is other than those listed above, describe it and name the principals:
§2. LICENSING
§2.1 List jurisdictions and trade categories in which your organization is legally qualified to do business, and indicate registration or license numbers, if applicable .
§2.2 List jurisdictions in whic h your organization 's partnership or trade name is filed.
§3. EXPERIENCE
§3.1 List the categories of work that your organization normally performs with its own forces.
§3.2 Claims and Suits. (If the answer to any of the questions below is yes, please attach details.)
§3.2.1 Has your organization ever fai led to complete any work awarded to it?
§3.2.2 Are there any judgments, claims, arbitration proceedings or suits pending or outstandi ng agai nst you r organization or its officers?
AlA Document A305™ -1 986. Copyright © 1964, 1969, 1979 and 1986 by The American Institute of Architects. All rights reserved. WARNING: This
3
AlA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AlA
document was produced by AlA software at 13:28:18 on 03/22/2006 under Order No.1 000201877_ 1 which expires on 10/ 11 /2006 , and is not for resale .
(2533789901 )
§3.2.3 Has your organization filed any law suits or requested arbitration with regard to construction contracts within the last five years?
§3.3 Within the last five years, has any officer or principal of your organization ever been an officer or principal of another organization when it failed to complete a construction contract? (If the answer is yes, please attach details.)
§3.4 On a separate sheet, list major construction projects your organization has in progress, giving the name of project, owner, architect, contract amount, percent complete and scheduled completion date.
§3.4.1 State total worth of work in progress and under contract:
§3.5 On a separate sheet, list the major projects your organization has completed in the past five years, giving the name of project, owner, architect, contract amount, date of completion and percentage of the cost of the work performed with your own forces.
§3.5.1 State average annual amount of construction work performed during the past five years:
§3.6 On a separate sheet, list the construction experience and present commitments of the key individuals of your organization.
AtA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA
4
document was produced by AIA software at 13:28:18 on 03/22/2006 under Order No.1000201877_1 which expires on 10/11/2006, and is not for resale.
§4. REFERENCES
§4.1 Trade References:
§4.2 Bank References:
§4.3 Surety:
§4.3.1 ame of bonding company:
§4.3.2 Name and address of agent:
§5. FINANCING
§5.1 Financial Statement.
§5.1.1 Attach a financial statement, preferably audited, including your organization's latest balance sheet and income statement showing the following items:
Current Assets (e.g., cash, joint venture accounts, accounts receivable, notes receivable, accrued income, deposits, materia ls inventory and prepaid expenses);
et Fixed Assets;
Other Assets;
Current Liabi li ties (e.g., accounts payable, notes payable, accrued expenses, provision for income taxes, adva nces, accrued salaries and accrued payroll taxes);
Other Liabilities (e.g ., capital , capital stock, authorized and outstandi ng shares par values, earned surplus and retai ned earnings).
§ 5.1.2 Name and add ress of firm preparing attached financial statement, and date thereof:
AlA Document A305™ - 1986. Copyright © 1964, 1969, 1979 and 1986 by The American Institute of Architects. All rights reserved. WARNING : This
5
document was produced by AlA software at 13:28:18 on 03/22/2006 under Order NO.1000201877_ 1 which expires on 10/ 11 /2006. and is not for resale.
§5.1.3 Is the attached financial statement for the identical organization named on page one?
§5.1.4 If not, explain the relationship and financial responsibility of the organization whose financial statement is provided (e.g. , parent-subsidiary) .
§5.2 Will the organization whose financial statement is attached act as guarantor of the contract for construction ?
§6. SIGNATURE
§ 6.1 Dated at this
day of
ame of Organization:
By:
Title:
§6.2
being du ly sworn deposes and says that the information provided herein is true and sufficiently complete so as not to be mis leading .
Subscribed and sworn before me this
20
Notary Public:
My Commission Expires:
AlA Document A305™ - 1986. Copyright © 1964, 1969, 1979 and 1986 by The American Institute of Architecls. All rights reserved. WARNING: This
6
document was produced by AlA software at t 3:28:18 on 03/22/2006 under Order NO .1000201877_ 1 which expires on 10/ 11 /2006 , and is not for resale .
Additions and Deletions Report for
AlA® Document A305TM - 1986
This Additions and Deletions Report , as defined on page 1 of the associated document, reproduces below all text the author has added to the standard form AlA document in order to complete it, as well as any text the author may have added to or deleted from the original AlA text. Added text is shown underlined. Deleted text is indicated with a horizontal line through the original AlA text.
Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part of the associated AlA document. This Additions and Deletions Report and its associated document were generated simultaneously by AlA software at 13:28:18 on 03/22/2006.
PAGE 6
M-being duly sworn deposes and says that the information provided herein is true and sufficiently complete so as not to be misleading.
Additions and Deletions Report for AlA Document A305™ -1986. Copyright © 1964, 1969, 1979 and 1986 by The American Instilute of Architects.
All
rights reserved. WARNING: This AlA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or
distribution of this AlA ' Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AlA software at 13:28:18 on 03/22/2006 under Order No .1 000201877_ 1 which expires on
10/11 /2006 , and is not for resale .
Certification of Document's Authenticity
AIA® Document D401™ - 2003
I, Charles V. Bucci , hereby certify, to the best of my knowledge, information and belief, that I created the attached final document simultaneously with its associated Additions and Deletions Report and this certification at 13:28: 18 on 03/22/2006 under Order No. 1000201877_1 from AIA Contract Documents software and that in preparing the attached fina l document I made no changes to the original text of AIA® Document A305™ - 1986 - Contractor's Qualification Statement, as published by the AIA in its software, other than those additions and deletions shown in the associated Additions and Deletions Report.
(Signed)
(Title)
(Dated)
AlA Document D40FM - 2003. Copyright © 1992 and 2003 by The American Institute of Architects. All rights reserved.
WARNING: This AlA- Document
Is protected by U.S. Copyright Law and International Treaties . Unauthorized reproduction or distribution of this AlA
Document, or any portion of it,
may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced
by AlA software at 13:28:18 on 03/22/2006 under Order No .1 000201877_ 1 which expires on 10/11 /2006 , and is not for resale.